Terms & Conditions

By accessing or using Durabuild's website and services, you agree to comply with these Terms & Conditions. These terms govern your use of our website, services, and any contractual relationships for construction projects.

Please read these terms carefully before using our website or engaging our services. If you do not agree with any part of these terms, you should not use our website or services.

By accessing this website or engaging Durabuild for construction services, you acknowledge that you have read, understood, and agree to be bound by these Terms & Conditions. These terms apply to all visitors, users, and clients of Durabuild's services.

Durabuild provides comprehensive construction, renovation, infrastructure, and related professional services including but not limited to:

• Construction Services: Residential, commercial, and industrial building construction.
• Infrastructure Development: Roads, bridges, water systems, and public works.
• Architecture & Planning: Design, planning, and structural engineering services.
• Renovation & Maintenance: Building upgrades, repairs, and ongoing maintenance.
• Material Supply: Sourcing and delivery of construction materials.

Project timelines, costs, and outcomes may vary based on site conditions, weather, regulatory approvals, and client requirements. All projects are subject to separate contracts that outline specific terms, deliverables, and payment schedules.

Project Contracts & Agreements

All construction projects require a formal written contract signed by both parties. The contract will include:

• Detailed scope of work and project specifications
• Project timeline and key milestones
• Total project cost and payment schedule
• Warranties, guarantees, and quality standards
• Terms for changes, delays, and dispute resolution
• Insurance and liability coverage

The project contract takes precedence over these general Terms & Conditions for project-specific matters.

• Accurate Information: Provide accurate, complete, and up-to-date project and contact information.
• Lawful Use: Use the website and services only for lawful purposes and in accordance with these terms.
• Site Access: Provide safe and timely site access for project execution and inspections.
• Permits & Approvals: Assist in obtaining necessary permits, approvals, and clearances as required.
• Payment: Make timely payments according to agreed schedules and terms.
• No Misuse: Do not attempt to harm, disrupt, or interfere with the website, services, or other users.

Intellectual Property

All content on this website, including text, graphics, logos, images, designs, videos, and software, is the intellectual property of Durabuild and is protected by copyright, trademark, and other intellectual property laws.

• You may not copy, reproduce, distribute, or create derivative works without written permission.
• The Durabuild name, logo, and branding are registered trademarks and may not be used without authorization.
• Project designs and architectural plans remain Durabuild's property unless ownership transfer is specified in the contract.
• Unauthorized use of our intellectual property may result in legal action.

Payment Terms

Payment terms are outlined in individual project contracts. General payment guidelines include:

• Advance payment or deposit may be required before project commencement.
• Progress payments are typically tied to project milestones or phases.
• Final payment is due upon project completion and client acceptance.
• Late payments may incur interest charges or project suspension.
• All payments must be made via authorized payment methods specified in the contract.

Durabuild is committed to delivering high-quality construction services. Our warranty commitments include:

• Structural warranty typically covers 5-10 years depending on the project type.
• Workmanship warranty covers defects in construction for a period specified in the contract.
• Material warranties are subject to manufacturer terms and conditions.
• Warranty does not cover damage from misuse, natural disasters, or lack of maintenance.
• Claims must be reported promptly with proper documentation for warranty coverage.

To the maximum extent permitted by law, Durabuild's liability is limited as follows:

• We are not liable for indirect, incidental, consequential, or punitive damages arising from the use of our website or services.
• Our total liability for any claim shall not exceed the total amount paid by the client for the specific project in question.
• We are not responsible for delays or failures caused by force majeure events, including natural disasters, pandemics, strikes, or government actions.
• Website content is provided "as is" without warranties of any kind, express or implied.
• We are not liable for third-party content, links, or services accessed through our website.

Dispute Resolution

In the event of any dispute arising from these terms or our services:

• Both parties agree to first attempt resolution through good-faith negotiation and mediation.
• If mediation fails, disputes shall be resolved through binding arbitration in accordance with applicable arbitration rules.
• The arbitration shall be conducted in the jurisdiction where Durabuild's principal office is located.
• The decision of the arbitrator shall be final and binding on both parties.

Service Changes & Termination

We reserve the right to update, modify, or discontinue services, website features, or content at any time with or without notice. This includes:

• Adding or removing website features and functionality
• Updating service offerings and pricing
• Suspending or terminating user accounts that violate these terms
• Temporarily restricting access for maintenance or upgrades

Active project contracts will be honored according to their specific terms, even if general services are modified or discontinued.

Governing Law

These Terms & Conditions are governed by and construed in accordance with the laws of India. Any legal action or proceeding arising from these terms shall be brought exclusively in the courts having jurisdiction in the location of Durabuild's registered office.

Severability

If any provision of these Terms & Conditions is found to be invalid, illegal, or unenforceable, the remaining provisions shall continue in full force and effect. The invalid provision shall be modified to the minimum extent necessary to make it valid and enforceable.

Changes to These Terms

Durabuild reserves the right to modify these Terms & Conditions at any time. Changes will be effective immediately upon posting on this page with an updated "Last Updated" date. Your continued use of the website or services after changes constitutes acceptance of the modified terms. We encourage you to review these terms periodically.